subcontractor agreement template qld

Independent Subcontractor Services Agreement

Instructions for Use

• Fill in all bracketed information throughout the document with the specific details of your engagement.
• Ensure all insurance certificates and relevant licenses are attached as an appendix before signing.
• Both parties should initial the bottom of each page and sign the final execution block to ensure enforceability under Queensland law.

1. Parties and Definitions

This Agreement is made on [Date] between:

Principal: [Principal Full Legal Name], ABN [__________], located at [Principal Address] ("Principal").

Subcontractor: [Subcontractor Full Legal Name], ABN [__________], located at [Subcontractor Address] ("Subcontractor").

Project: [Brief description of the project or scope of work].

2. Services

The Subcontractor agrees to perform the services described in the Scope of Work (attached as Annexure A) in a professional and workmanlike manner, in accordance with all applicable Queensland building codes, industry standards, and safety regulations.

3. Term and Termination

3.1 This Agreement commences on [Start Date] and continues until [Completion Date] or until the Project is completed. 3.2 Either party may terminate this Agreement with [Number] days' written notice if the other party commits a material breach of these terms.

4. Payment

4.1 The Principal shall pay the Subcontractor [Amount] (plus GST) for services rendered. 4.2 Payment shall be made within [Number] days of receipt of a valid tax invoice. 4.3 The Subcontractor is responsible for all their own tax obligations, superannuation, and workers' compensation insurance.

5. Independent Contractor Status

The Subcontractor is an independent contractor, not an employee. Nothing in this Agreement creates a partnership, joint venture, or employer-employee relationship.

6. Insurance and Licenses

6.1 The Subcontractor must maintain, at their own expense:

• Public Liability Insurance (minimum $__________ coverage)
• Professional Indemnity Insurance (if applicable)
• Workers' Compensation Insurance (as required by Queensland law) 6.2 The Subcontractor warrants they hold all necessary licenses required by the Queensland Building and Construction Commission (QBCC) to perform the work.

7. Indemnity and Liability

The Subcontractor agrees to indemnify and hold harmless the Principal against any claims, losses, or damages arising from the Subcontractor’s negligence or breach of this Agreement.

8. Governing Law

This Agreement is governed by the laws of Queensland, Australia. Any disputes shall be submitted to the exclusive jurisdiction of the courts of Queensland.

9. Entire Agreement

This document constitutes the entire agreement between the parties and supersedes all prior discussions or representations.

Execution

Signed for and on behalf of the Principal: Signature: __________ Printed Name: __________ Title: __________ Date: __________

Signed for and on behalf of the Subcontractor: Signature: __________ Printed Name: __________ Title: __________ Date: __________

Legal Disclaimer: This document is a general framework intended for informational purposes only. It does not constitute legal advice. You must consult with a qualified legal professional to ensure this agreement complies with specific Queensland legislation, including the Building Industry Fairness (Security of Payment) Act 2017.